Terms & Conditions

1. Agreement to Terms

These Terms and Conditions ("Terms") constitute a legally binding agreement between you ("Client," "you," or "your") and Anew Home Interioa ("Company," "we," "our," or "us") regarding your use of our website anewhomeinterioa.com and interior design services.

By accessing our website, engaging our services, or entering into a design contract with us, you agree to be bound by these Terms. If you do not agree to these Terms, please do not use our website or services.

2. Services Description

Anew Home Interioa provides professional interior design services, including but not limited to:

• Residential interior design and space planning
• Design consultations and concept development
• Furniture selection and procurement
• Color and material specification
• Project management and coordination
• Custom design solutions

Specific services will be detailed in individual service agreements or contracts.

3. Client Responsibilities

3.1 Information and Access

Clients agree to:

• Provide accurate and complete information about project requirements
• Grant reasonable access to the property for design work
• Respond promptly to requests for decisions and approvals
• Disclose any relevant property restrictions or limitations
• Obtain necessary permits and approvals as required

3.2 Payment Obligations

Clients are responsible for:

• Timely payment of all fees as specified in the service agreement
• Additional costs arising from changes to the original scope
• Third-party expenses (contractors, materials, permits) unless otherwise agreed
• Late payment fees as specified in individual contracts

4. Design Process and Approvals

4.1 Design Development

Our design process typically includes:

• Initial consultation and needs assessment
• Concept development and presentation
• Design refinement based on client feedback
• Final design documentation and specifications
• Implementation support and project management

4.2 Client Approval

Client approval is required at key milestones. Once approved, changes may result in additional fees. We are not responsible for delays caused by client's failure to provide timely approvals.

5. Intellectual Property Rights

5.1 Design Ownership

All design concepts, drawings, specifications, and creative work remain the intellectual property of Anew Home Interioa until full payment is received. Upon full payment, clients receive a license to use the designs for the specific project.

5.2 Portfolio Rights

We reserve the right to photograph completed projects and use images for marketing, portfolio, and promotional purposes unless otherwise agreed in writing.

6. Pricing and Payment Terms

6.1 Fee Structure

Our fees may be structured as:

• Fixed project fees
• Hourly rates for consultation services
• Percentage of project cost
• Combination of the above

6.2 Payment Schedule

Payment terms will be specified in individual service agreements. Typically:

• Initial deposit required to commence work
• Progress payments tied to project milestones
• Final payment due upon project completion
• Late payments may incur interest charges

7. Project Timeline and Delays

Project timelines are estimates based on normal working conditions. We are not responsible for delays caused by:

• Client changes or delayed approvals
• Permit delays or regulatory issues
• Contractor or supplier delays
• Force majeure events (natural disasters, pandemics, etc.)
• Unforeseen site conditions

8. Changes and Modifications

Changes to the original scope of work must be agreed upon in writing and may result in:

• Additional fees for design modifications
• Extended project timelines
• Revised terms and conditions

We reserve the right to charge for excessive revisions beyond what is reasonable for the project scope.

9. Cancellation and Termination

9.1 Client Cancellation

Clients may cancel services with written notice. Cancellation terms:

• Payment due for all work completed to date
• Non-refundable deposits as specified in service agreements
• Responsibility for any committed third-party costs

9.2 Company Termination

We may terminate services for:

• Non-payment of fees
• Breach of contract terms
• Unreasonable client demands or behavior
• Safety concerns

10. Warranties and Disclaimers

10.1 Design Services Warranty

We warrant that our design services will be performed with professional skill and care consistent with industry standards. This warranty is limited to the correction of design errors at no additional charge.

10.2 Third-Party Products and Services

We do not warrant third-party products, materials, or contractor services. Manufacturer warranties apply to products, and contractor warranties apply to installation work.

10.3 Disclaimer

EXCEPT AS EXPRESSLY STATED, ALL SERVICES ARE PROVIDED "AS IS" WITHOUT WARRANTIES OF ANY KIND, EXPRESS OR IMPLIED, INCLUDING WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.

11. Limitation of Liability

Our liability is limited to the total amount paid for our design services. We are not liable for:

• Indirect, consequential, or punitive damages
• Loss of profits or business interruption
• Third-party contractor or supplier performance
• Product defects or installation issues
• Damages exceeding the contract value

12. Insurance and Indemnification

We maintain professional liability insurance. Clients agree to indemnify us against claims arising from:

• Client's failure to obtain required permits
• Modifications made without our involvement
• Third-party contractor negligence
• Property damage not caused by our negligence

13. Dispute Resolution

13.1 Mediation

Disputes will first be addressed through good faith negotiation. If unsuccessful, disputes will be resolved through binding mediation in California.

13.2 Arbitration

If mediation fails, disputes will be resolved through binding arbitration under California law. The prevailing party may recover reasonable attorney fees.

14. Force Majeure

We are not liable for delays or failures due to circumstances beyond our reasonable control, including:

• Natural disasters or extreme weather
• Government actions or regulations
• Labor strikes or shortages
• Supply chain disruptions
• Pandemics or health emergencies

15. Confidentiality

We respect client privacy and maintain confidentiality of:

• Personal and financial information
• Property details and security information
• Family and lifestyle preferences
• Business or professional information

This confidentiality survives termination of our services.

16. Website Terms of Use

16.1 Acceptable Use

When using our website, you agree not to:

• Violate any applicable laws or regulations
• Infringe on intellectual property rights
• Transmit harmful or malicious code
• Attempt unauthorized access to our systems
• Use the site for commercial purposes without permission

16.2 Content Accuracy

While we strive for accuracy, we do not warrant that website content is complete, current, or error-free. Information is subject to change without notice.

17. Privacy and Data Protection

Our collection and use of personal information is governed by our Privacy Policy, which is incorporated by reference into these Terms. By using our services, you consent to our privacy practices.

18. Governing Law

These Terms are governed by California state law without regard to conflict of law principles. Any legal action must be brought in California courts.

19. Severability

If any provision of these Terms is found unenforceable, the remaining provisions will continue in full force and effect.

20. Entire Agreement

These Terms, together with any signed service agreements, constitute the entire agreement between parties and supersede all prior negotiations, representations, or agreements.

21. Modifications

We may update these Terms periodically. Changes will be posted on our website with the effective date. Continued use of our services constitutes acceptance of modified Terms.

22. Contact Information

For questions about these Terms or our services, please contact us:

23. Effective Date

These Terms are effective as of January 1, 2025, and apply to all services and website usage on or after this date.